The Collaboration Agreement with Builder is essential when multiple construction entities need to work together on building projects in England and Wales. This document is particularly relevant for complex construction projects requiring specialized expertise or resource sharing. It addresses key aspects such as work scope, risk sharing, payment structures, and project management protocols while ensuring compliance with UK construction regulations and best practices. The agreement helps prevent disputes by clearly defining roles, responsibilities, and expectations of all parties involved.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. 1. Parties: Identifies and defines the collaborating parties including their registered addresses and company details
2. 2. Background: Sets out the context of the collaboration and what each party brings to the arrangement
3. 3. Definitions: Defines key terms used throughout the agreement including technical construction terms
4. 4. Scope of Works: Details the specific construction works to be undertaken, including specifications and standards
5. 5. Project Timeline: Outlines key dates, milestones, and completion deadlines
6. 6. Payment Terms: Details payment structure, amounts, timing, and payment notice requirements under the Construction Act
7. 7. Obligations and Responsibilities: Lists specific duties of each party including compliance with building regulations and health & safety requirements
8. 8. Insurance and Liability: Specifies required insurance coverage, liability limitations, and indemnities
9. 9. Termination: Sets out circumstances and process for ending the agreement, including consequences of termination
1. Intellectual Property Rights: Addresses ownership of designs, innovations, and construction methods - used when design work or innovative construction methods are involved
2. Confidentiality: Protects sensitive information and trade secrets - used when proprietary information will be shared between parties
3. Force Majeure: Addresses unforeseen circumstances and their impact on the project - recommended for longer-term projects
4. Dispute Resolution: Sets out specific procedures for resolving disputes, including adjudication provisions under the Construction Act
5. Environmental Compliance: Details environmental obligations and waste management requirements - used for projects with significant environmental impact
1. Schedule 1 - Detailed Scope of Works: Comprehensive breakdown of construction works, specifications, and quality standards
2. Schedule 2 - Payment Schedule: Detailed payment terms, milestone payments, and payment notice requirements
3. Schedule 3 - Project Timeline: Detailed project program, milestones, and critical path activities
4. Schedule 4 - Insurance Requirements: Specific insurance policies and coverage levels required for the project
5. Appendix A - Site Plans and Drawings: Technical drawings, site specifications, and any relevant planning permissions
6. Appendix B - Health and Safety Requirements: Specific H&S protocols, risk assessments, and CDM requirements
Authors
Relevant legal definitions
Clauses
Relevant Industries
Relevant Teams
Relevant Roles
Find the exact document you need
Technology Collaboration Agreement
An England & Wales legal agreement for joint technology development, detailing IP rights, confidentiality, and risk sharing.
find out more
Song Collaboration Agreement
An England & Wales contract outlining terms for musical collaboration, including ownership, contributions, and revenue sharing.
find out more
Software Collaboration Agreement
An England & Wales legal document outlining collaboration terms for joint software development projects.
find out more
Business Collaboration Contract
An England & Wales agreement defining the professional relationship and obligations between a property owner and architect.
find out more
Author Illustrator Collaboration Agreement
An England & Wales legal framework for interior construction, detailing scope, payment, and compliance obligations.
find out more
Artist Collaboration Contract
An England & Wales agreement outlining commission terms for independent sales contractors and ensuring compliance with relevant legislation.
find out more
Collaboration Agreement With Builder
A legal agreement under English and Welsh law establishing terms for collaboration between construction parties in building projects.
find out more
Property Collaboration Agreement
A legal agreement under English and Welsh law establishing terms for parties to collaborate on property-related projects.
find out more
Co Writer Agreement
A legal agreement under English and Welsh law establishing terms between musical collaborators for joint songwriting projects.
find out more
Founder Collaboration Agreement
A legally binding agreement under English and Welsh law that establishes the framework for cooperation between founders in establishing and running a business venture.
find out more
Master Collaboration Agreement
A foundational agreement under English and Welsh law establishing terms for ongoing collaboration between multiple parties.
find out more
Exclusive Collaboration Agreement
A legally binding agreement establishing exclusive partnership terms between parties, governed by English and Welsh law.
find out more
Collaboration Contract Agreement
A legally binding agreement under English and Welsh law that establishes terms for parties to collaborate on projects or initiatives.
find out more
Collaboration Research Agreement
A legal framework under English and Welsh law governing joint research activities between multiple parties, addressing IP rights, confidentiality, and project governance.
find out more
³Ò±ð²Ô¾±±ð’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ³Ò±ð²Ô¾±±ð’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)