The Contractor Agreement For House (Construction) is a specialized legal document designed for use in Hong Kong's residential construction sector. It serves as the primary contract between property owners and construction contractors, establishing their rights, obligations, and responsibilities throughout the building process. This agreement is particularly important in Hong Kong's complex regulatory environment, where strict building codes and safety standards must be adhered to. The document incorporates requirements from the Buildings Ordinance (Cap. 123) and related legislation, while addressing practical aspects such as payment schedules, construction timelines, and quality standards. It's essential for any residential construction project in Hong Kong, providing protection for both parties and ensuring compliance with local construction laws and regulations.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the property owner/employer and the contractor, including full legal names and addresses
2. Background: Context of the agreement, including property details and purpose of construction
3. Definitions and Interpretation: Definition of key terms used throughout the agreement and rules of interpretation
4. Scope of Works: Detailed description of construction works to be performed, including specifications and standards
5. Contract Sum and Payment Terms: Total contract price, payment schedule, and payment conditions
6. Commencement and Completion: Project timeline, completion date, and provisions for extensions of time
7. Contractor's Obligations: Key responsibilities including workmanship, materials, safety, and regulatory compliance
8. Employer's Obligations: Property owner's responsibilities including site access, permits, and information provision
9. Variations: Process for managing changes to scope, pricing, and approval of variations
10. Quality and Inspection: Quality standards, inspection procedures, and acceptance criteria
11. Insurance and Indemnity: Required insurance coverage and indemnification obligations
12. Defects Liability: Defects liability period, rectification obligations, and warranty terms
13. Termination: Grounds and procedures for contract termination by either party
14. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration
15. General Provisions: Standard contract clauses including notices, governing law, and entire agreement
1. Performance Bond: Required when additional security for performance is needed, specifying bond terms and conditions
2. Liquidated Damages: Include when specific compensation for delay or performance failure needs to be pre-agreed
3. Environmental Protection: Detailed environmental requirements for environmentally sensitive projects or locations
4. Subcontracting: Include when subcontracting will be permitted, specifying conditions and approval requirements
5. Site Safety Management: Detailed safety requirements for high-risk or complex projects
6. Intellectual Property Rights: Include when design elements or innovative construction methods are involved
7. Force Majeure: Detailed provisions for handling unforeseen events, particularly relevant in long-term projects
8. Retention: Include when payment retention is required as security for performance
9. Testing and Commissioning: Required for projects involving mechanical, electrical, or specialized systems
1. Schedule 1 - Drawings and Specifications: Detailed construction drawings, technical specifications, and design documents
2. Schedule 2 - Bill of Quantities: Itemized list of materials, quantities, and prices
3. Schedule 3 - Payment Schedule: Detailed breakdown of payment milestones and amounts
4. Schedule 4 - Construction Program: Detailed project timeline, milestones, and critical path
5. Schedule 5 - Site Details: Site plan, access points, utilities information, and site conditions
6. Schedule 6 - Required Insurances: List of required insurance policies and coverage amounts
7. Schedule 7 - Key Personnel: List of key project personnel and their roles/responsibilities
8. Schedule 8 - Permits and Approvals: List of required regulatory permits and approvals
9. Appendix A - Quality Assurance Plan: Detailed quality control procedures and standards
10. Appendix B - Safety Management Plan: Site safety procedures and requirements
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate
Architecture
Engineering
Property Development
Building Materials
Construction Insurance
Property Management
Interior Design
Environmental Services
Relevant Teams
Legal
Construction
Project Management
Procurement
Risk and Compliance
Property Development
Technical Services
Contract Administration
Quality Assurance
Operations
Relevant Roles
Construction Manager
Project Director
Legal Counsel
Contract Administrator
Property Developer
Site Manager
Quantity Surveyor
Building Surveyor
Procurement Manager
Risk Manager
Compliance Officer
Construction Lawyer
Property Manager
Technical Director
Chief Engineer
Find the exact document you need
Standard Release Of Liability Form
A Hong Kong law-governed document where one party waives their right to legal claims against another party for specified activities or incidents.
find out more
Primary Non Contributory Endorsement Form
A Hong Kong-compliant insurance endorsement that establishes primary coverage and non-contributory status for an existing insurance policy.
find out more
Contract Between Customer And Supplier
A Hong Kong law-governed contract template establishing terms and conditions between a customer and supplier, suitable for both B2B and B2C relationships.
find out more
Agreement Between Company And Contractor
A Hong Kong law-governed agreement establishing terms and conditions between a company and independent contractor, defining service scope and commercial relationship.
find out more
Contractor Agreement For House (Construction)
Hong Kong-governed construction contract between property owner and contractor for residential building works, compliant with local building regulations.
find out more
General Terms Of Contract
A Hong Kong law-governed master agreement establishing standard terms and conditions for future business transactions between parties.
find out more
Framework Agreement (Construction)
A Hong Kong law-governed agreement establishing terms for ongoing construction services between an employer and contractor, with provisions for individual project call-offs.
find out more
Person Centred Risk Assessment
A Hong Kong-compliant person-centered risk assessment tool for evaluating and managing individual risks in healthcare and social care settings.
find out more
Short Form Non Disclosure Agreement
A concise Hong Kong law-governed NDA for protecting confidential information in standard business discussions and commercial relationships.
find out more
Resident Declaration Form
A legal document under Hong Kong law for declaring and verifying an individual's residential status within the Hong Kong SAR.
find out more
Hourly Rate Agreement
A Hong Kong law-governed agreement setting out terms and conditions for hourly-rate based service provision, including payment terms and service scope.
find out more
Standard Software License Agreement
A Hong Kong law-governed agreement setting out terms and conditions for software licensing, including usage rights, IP protection, and compliance requirements.
find out more
Business Contract Termination Letter
A formal letter governed by Hong Kong law that officially terminates a business contract, specifying termination terms and post-termination obligations.
find out more
Construction Invoice
A legally compliant construction billing document used in Hong Kong that details completed works, materials, and services for payment processing.
find out more
Mail For Salary Increment
A Hong Kong-compliant formal letter documenting an employee's salary increase and related employment term modifications.
find out more
General Tenancy Agreement
A Hong Kong law-governed agreement establishing terms and conditions for property rental between landlord and tenant.
find out more
Legal Agreement Between Two Parties
A Hong Kong law-governed bilateral agreement template for formalizing business relationships and contractual obligations between two parties.
find out more
Non Compete Employment Contract
A Hong Kong law-governed employment agreement containing non-compete provisions to protect business interests while maintaining enforceability under local law.
find out more
Liability Agreement
A Hong Kong law-governed agreement defining liability allocation and risk management between business parties.
find out more
Agreement Between Company And Labour Contractor
A Hong Kong law-governed agreement establishing terms for labour contractor services, including worker provision, management responsibilities, and regulatory compliance requirements.
find out more
Sub Contract Work Agreement
A Hong Kong law-governed agreement between main contractor and subcontractor defining terms for specific construction or development works.
find out more
Simple Separation Agreement
A Hong Kong law-governed agreement that establishes legally binding terms for married couples to live separately, including arrangements for assets, finances, and other practical matters.
find out more
Property Agreement Between Two Parties
A Hong Kong law-governed agreement between two parties for the sale and purchase of property, detailing transaction terms and mutual obligations.
find out more
Labour Hire Contract
A Hong Kong-governed agreement establishing terms for labor hire arrangements between a staffing company, worker, and host company.
find out more
Labour Hire Agreement
A Hong Kong law-governed agreement between a labor hire agency and host employer for the provision of temporary workers, ensuring compliance with local employment regulations.
find out more
Laboratory Risk Assessment Form
A Hong Kong-compliant laboratory risk assessment document for identifying, evaluating, and controlling potential hazards in laboratory settings.
find out more
House Ownership Contract
A Hong Kong law-governed agreement for the transfer of residential property ownership, detailing all essential terms and conditions of the sale.
find out more
General Affidavit Form
A formal written statement of facts sworn under oath or affirmation under Hong Kong law, executed before an authorized person and used as legal evidence or testimony.
find out more
Contractor Subcontractor Agreement
A Hong Kong law-governed agreement between contractor and subcontractor defining terms, conditions, and obligations for construction works.
find out more
Cleaning Contract Termination Letter
A Hong Kong law-governed letter formally terminating a cleaning services contract, outlining termination terms and final arrangements between parties.
find out more
Business Development Contract
A Hong Kong law-governed agreement establishing terms and conditions for business development services, including scope, performance metrics, and compensation structure.
find out more
Swimming Consent Form
A Hong Kong law-governed consent form for swimming activities, capturing participant information, medical declarations, and safety acknowledgments.
find out more
Staffing Agency Contract With Client
A Hong Kong-governed agreement between a staffing agency and client company for the provision of temporary workers, establishing service terms and compliance requirements.
find out more
Simple Stock Transfer Agreement
A Hong Kong law-governed agreement for the transfer of shares between parties, including standard transfer provisions and local regulatory requirements.
find out more
Self Employed Agreement
A Hong Kong law-governed agreement establishing an independent contractor relationship between a company and a self-employed individual.
find out more
Owner Consent Letter
A Hong Kong-compliant formal letter where a property owner provides written consent for specific property-related activities or modifications.
find out more
Part Bill Of Lading
A Hong Kong law-governed shipping document that serves as a partial receipt, contract of carriage, and document of title for a portion of cargo in maritime transport.
find out more
Label Contract
A Hong Kong-governed agreement between a record label and artist(s) establishing terms for music recording, distribution, and rights management.
find out more
Home Remodel Contract
A Hong Kong-governed contract for residential renovation work, outlining terms between homeowner and contractor while ensuring compliance with local building regulations.
find out more
General Contract Agreement Between Two Parties
A general-purpose contract agreement template governed by Hong Kong law, designed for formal business relationships between two parties.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)