The Residential Construction Contract is a foundational document used in Ireland for managing legal relationships between homeowners and building contractors in residential construction projects. It is specifically designed to comply with Irish construction law, including the Construction Contracts Act 2013, Building Control Regulations, and consumer protection legislation. This document is essential when undertaking any significant residential construction work, from new builds to major renovations, and includes detailed provisions for scope of works, payment structures, quality standards, and dispute resolution mechanisms. The contract protects both parties' interests while ensuring compliance with Irish building regulations and construction industry standards. It is particularly important given the specific requirements of Irish construction law regarding payment practices, certification, and building control.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the homeowner(s) and the contractor, including full legal names, addresses, and registration numbers
2. Background: Context of the agreement, including property details and brief project overview
3. Definitions: Defined terms used throughout the contract, ensuring clarity and consistent interpretation
4. Scope of Works: Detailed description of the construction work to be performed, including general specifications and standards
5. Contract Price and Payment Terms: Total contract value, payment schedule, stage payments, and payment procedures
6. Commencement and Completion: Start date, completion date, and provisions for extensions of time
7. Contractor Obligations: Key responsibilities of the contractor, including quality standards, materials, and workmanship
8. Client Obligations: Responsibilities of the homeowner, including access, permissions, and decision-making timeframes
9. Variations: Process for managing changes to the scope of works and their impact on price and timeline
10. Insurance and Liability: Required insurance coverage and allocation of risks between parties
11. Warranties and Defects: Warranties provided, defects liability period, and rectification procedures
12. Termination: Circumstances and procedures for contract termination by either party
13. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
14. General Provisions: Standard legal clauses including notices, assignment, and governing law
1. Planning Permission: Details of planning requirements and responsibilities - include when planning permission is required for the works
2. Professional Team: Roles and responsibilities of architects, engineers, and other professionals - include when project requires professional appointments
3. Site Security: Specific provisions for securing the construction site - include for larger projects or sensitive locations
4. Environmental Requirements: Special environmental considerations and obligations - include when project has specific environmental impacts
5. Utilities and Services: Arrangements for temporary and permanent utilities - include when significant utility works are required
6. Neighbor Relations: Procedures for managing neighbor relations and party wall matters - include in urban settings or attached properties
7. Storage of Materials: Requirements for material storage and security - include for larger projects with significant material storage needs
8. Living Arrangements: Provisions for occupants during construction - include when property will remain occupied during works
1. Schedule 1: Detailed Scope of Works: Comprehensive specifications, drawings, and technical details of the construction work
2. Schedule 2: Contract Price Breakdown: Detailed cost breakdown including materials, labor, and other components
3. Schedule 3: Payment Schedule: Detailed stage payment schedule with trigger points and amounts
4. Schedule 4: Construction Program: Detailed timeline of works including key milestones and critical path
5. Schedule 5: Insurance Requirements: Specific insurance policies and coverage levels required
6. Schedule 6: Planning and Building Control Documents: Copies of relevant permissions, certificates, and compliance documents
7. Schedule 7: Material Specifications: Detailed specifications of materials to be used in construction
8. Appendix A: Drawings: All architectural, structural, and technical drawings
9. Appendix B: Health and Safety Plan: Safety procedures and risk assessments
10. Appendix C: Quality Control Procedures: Quality assurance measures and inspection procedures
Find the exact document you need
Subcontractor Contract For (Construction)
An Irish law-compliant construction subcontractor agreement governing the relationship between main contractor and subcontractor for specific construction works.
Download
Joint Venture Contract In (Construction)
An Irish law-governed agreement establishing a joint venture between construction companies, defining their rights, responsibilities, and operational framework for construction projects.
Download
Construction Payment Agreement
An Irish law-governed agreement establishing payment terms and mechanisms for construction projects, compliant with the Construction Contracts Act 2013.
Download
Collateral Warranty Agreement
An Irish law agreement creating direct contractual relationships between parties in construction projects who are not in direct contract, providing warranties and undertakings regarding work quality and professional obligations.
Download
Standard Contractor Contract
An Irish law-governed agreement establishing terms and conditions between a business and an independent contractor, defining services, payments, and mutual obligations.
Download
Home Construction Contract
An Irish law-governed contract between a homeowner and contractor for residential construction works, compliant with Irish construction regulations and consumer protection laws.
Download
Builder And Land Owner Agreement
An Irish law-governed agreement between a builder and land owner establishing terms and conditions for construction works.
Download
Contract For Builder And Client
An Irish law-governed construction agreement between a builder and client, defining project scope, terms, and mutual obligations.
Download
Contractor Contingency Agreement
An Irish law-governed agreement establishing contractor relationship terms and contingency arrangements between a company and contractor.
Download
Basic Construction Contract
An Irish law-governed construction contract establishing core rights and obligations between an employer and contractor for construction works.
Download
Builder Development Agreement
An Irish law-governed agreement between a developer and builder establishing terms and conditions for construction works execution.
Download
Home Builder Contract
An Irish law-governed contract between a builder and homeowner for residential property construction, incorporating Irish building regulations and construction standards.
Download
Residential Construction Contract
Irish residential construction contract governing agreements between homeowners and contractors, compliant with Irish construction laws and building regulations.
Download
Building Work Agreement
An Irish law-governed agreement establishing terms and conditions between property owner and contractor for construction works, compliant with Irish construction regulations and standards.
Download
New Construction Home Contract
An Irish law-governed contract for new residential property construction, establishing terms between builder and homebuyer.
Download
Contract For Contractor And Homeowner
An Irish law-governed contract between a contractor and homeowner for residential construction or renovation works, outlining project scope, terms, and mutual obligations.
Download
Construction Equipment Lease Agreement
An Irish law-governed agreement for leasing construction equipment, defining terms, conditions, and responsibilities between equipment owner and renter.
Download
Construction Work Order Agreement
An Irish law-governed agreement establishing terms and conditions for construction works, ensuring compliance with the Construction Contracts Act 2013 and related regulations.
Download
Construction Service Agreement
An Irish law-governed agreement establishing terms and conditions for construction services, incorporating key requirements from Irish construction legislation and industry standards.
Download
Construction Project Agreement
An Irish law-governed agreement establishing terms and conditions for construction projects, ensuring compliance with the Construction Contracts Act 2013 and related legislation.
Download
Buyer Builder Agreement
An Irish law-governed agreement between a buyer and builder setting out terms and conditions for construction works, including scope, payments, and obligations.
Download
Construction Subcontract
Irish law construction subcontract agreement establishing terms between main contractor and subcontractor, compliant with Construction Contracts Act 2013.
Download
Remodeling Contractor Agreement
An Irish law-governed agreement between property owners and contractors for remodeling works, compliant with Irish construction regulations and standards.
Download
Contract Agreement For Construction Work
An Irish law-governed agreement establishing terms and conditions between client and contractor for construction works, ensuring compliance with Irish construction legislation and industry standards.
Download
Standard Construction Contract
Irish law-governed standard construction contract establishing terms between employers and contractors, incorporating key requirements of Irish construction legislation.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)