The Design And Build Agreement is utilized in construction projects where a single contractor is responsible for both design and construction phases, streamlining project delivery and reducing coordination risks. This contract type is particularly relevant in the Indian construction sector, where integrated project delivery methods are increasingly favored. The agreement addresses specific Indian legal requirements, including compliance with the Indian Contract Act, RERA regulations, and state-specific building codes. It typically includes comprehensive provisions for design development, construction methodology, quality control, payment mechanisms, and dispute resolution tailored to the Indian legal system. The document is structured to protect both employer and contractor interests while ensuring clarity in risk allocation and project execution responsibilities.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the employer and the design-build contractor
2. Background: Context of the project and purpose of the agreement
3. Definitions and Interpretation: Definitions of key terms and interpretation rules
4. Scope of Work: Detailed description of design and construction obligations
5. Contract Documents: Hierarchy and list of contract documents
6. Designer's Obligations: Specific responsibilities related to design services
7. Contractor's Obligations: Construction and general obligations of the contractor
8. Employer's Obligations: Responsibilities of the employer including site access and permits
9. Contract Price and Payment: Price, payment terms, and mechanisms
10. Time for Completion: Project schedule, milestones, and completion dates
11. Design Development and Approval: Process for design submission, review, and approval
12. Quality Assurance and Control: Quality standards, testing, and inspection requirements
13. Variations: Procedures for changes to scope or specifications
14. Risk and Insurance: Risk allocation and required insurance coverage
15. Defects Liability: Defect correction period and obligations
16. Force Majeure: Force majeure events and consequences
17. Suspension and Termination: Rights and procedures for suspension and termination
18. Dispute Resolution: Dispute resolution procedures including arbitration
19. Governing Law and Jurisdiction: Applicable law and jurisdiction provisions
1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects
2. Intellectual Property Rights: IP ownership and licensing provisions, important for projects with significant design innovation
3. Environmental Compliance: Specific environmental obligations, necessary for environmentally sensitive projects
4. Site Security: Security requirements for high-risk or sensitive locations
5. Technology Transfer: Provisions for technology transfer, relevant for projects involving new technologies
6. Local Content Requirements: Local sourcing obligations, important for government projects
7. Step-in Rights: Employer's right to step in, relevant for critical infrastructure projects
8. Commissioning and Testing: Detailed commissioning procedures, important for complex facilities
1. Schedule 1 - Scope of Works: Detailed technical specifications and scope description
2. Schedule 2 - Project Schedule: Detailed timeline, milestones, and completion dates
3. Schedule 3 - Payment Schedule: Detailed payment terms, milestones, and amounts
4. Schedule 4 - Design Criteria: Technical design requirements and standards
5. Schedule 5 - Site Details: Site information, surveys, and existing conditions
6. Schedule 6 - Forms of Certificates: Templates for various certificates including completion certificates
7. Schedule 7 - Testing and Commissioning: Testing requirements and acceptance criteria
8. Schedule 8 - Insurance Requirements: Detailed insurance obligations and coverage requirements
9. Schedule 9 - Performance Standards: Performance specifications and acceptance criteria
10. Schedule 10 - Forms of Bonds and Guarantees: Templates for required bonds and guarantees
11. Appendix A - Drawing List: List of all drawings and specifications
12. Appendix B - Permits and Approvals: List of required permits and responsible parties
Authors
Relevant legal definitions
Clauses
Relevant Industries
Construction
Infrastructure
Real Estate Development
Industrial
Healthcare
Education
Hospitality
Commercial Development
Residential Development
Manufacturing
Technology Parks
Renewable Energy
Transportation
Retail
Relevant Teams
Legal
Construction
Engineering
Architecture
Project Management
Commercial
Procurement
Risk Management
Quality Assurance
Operations
Finance
Technical Services
Business Development
Contract Administration
Relevant Roles
Project Director
Construction Manager
Contract Manager
Legal Counsel
Project Manager
Chief Engineer
Design Manager
Procurement Manager
Commercial Manager
Risk Manager
Quality Control Manager
Technical Director
Operations Director
Chief Architect
Development Manager
Finance Director
Find the exact document you need
Preconstruction Agreement
An Indian law agreement governing pre-construction services, including planning, design review, and cost estimation for construction projects.
find out more
Joint Check Agreement In (Construction)
An Indian law-compliant agreement establishing joint payment mechanisms between contractors, subcontractors, and suppliers in construction projects.
find out more
Home Remodeling Contractor Agreement
An Indian law-governed agreement between homeowner and contractor for residential renovation works, detailing project scope, terms, and obligations.
find out more
Construction Agreement With Builder
An Indian law-governed agreement between property owner/developer and builder establishing terms for construction works, including scope, payments, and obligations.
find out more
Agreement Letter For (Construction)
An Indian law-compliant contractual document establishing terms between a contractor and client for construction works, outlining project specifics and legal obligations.
find out more
Project Consortium Agreement
An Indian law-governed agreement establishing a consortium of multiple parties for collaborative project execution, defining rights, responsibilities, and operational framework.
find out more
Land Purchase Proposal
An Indian law-compliant proposal document outlining terms and conditions for a land purchase transaction, serving as the basis for subsequent legal documentation.
find out more
Framework Agreement (Construction)
An Indian law-governed agreement establishing standard terms and procedures for ongoing construction services between a service provider and client.
find out more
Design Agreement For (Construction)
An Indian law-governed agreement establishing terms for professional design services in construction projects, including scope, deliverables, and responsibilities.
find out more
Mine Lease Agreement
A legal agreement governed by Indian mining laws that grants mineral extraction rights to a mining company, subject to specified terms and conditions.
find out more
Turnkey Project Agreement
An Indian law-governed agreement for complete project delivery, covering design through commissioning, with contractor assuming full turnkey responsibility.
find out more
Design And Build Agreement
An Indian law-governed agreement combining design and construction responsibilities into a single contract between project owner and design-build contractor.
find out more
Subcontractor Work Order
An Indian law-compliant agreement between a main contractor and subcontractor specifying work scope, terms, and compliance requirements for delegated project tasks.
find out more
Project Financing Agreement
An Indian law-governed agreement establishing terms and conditions for project financing facilities, including loan terms, security arrangements, and project undertakings.
find out more
Mural Agreement
An Indian law-governed agreement establishing terms for mural artwork creation, including artistic specifications, rights, and obligations of artists and commissioners.
find out more
Non Disclosure Agreement For Design Work
An India-compliant NDA specifically designed to protect confidential design work, including physical and digital design assets under Indian law.
find out more
Design Build Maintain Contract
An Indian law-governed integrated contract template combining design, construction, and maintenance obligations into a single agreement.
find out more
Design Build Lump Sum Contract
An Indian law-governed contract template for design-build projects with fixed price arrangements, combining design and construction responsibilities under a single contractor.
find out more
Residential Architect Contract
An Indian jurisdiction agreement governing professional architectural services for residential property design and development projects.
find out more
Project Based Employment Agreement
An Indian law-compliant employment agreement for temporary project-based work, defining project scope, terms, and deliverables.
find out more
Project Based Agreement
An Indian law-governed agreement establishing terms and conditions for project-based work, including scope, deliverables, timelines, and responsibilities.
find out more
Freelance Project Contract
An Indian law-governed contract establishing terms and conditions between a freelancer and client for project-based work.
find out more
Construction Agreement Between Client And Contractor
An Indian law-governed agreement between a client and contractor defining construction project terms, obligations, and deliverables.
find out more
IT Project Agreement
A legal agreement for IT project delivery and services, governed by Indian law and regulations.
find out more
Collaboration Agreement For Construction Of Building
An Indian law-governed agreement establishing terms for collaboration between parties in a building construction project, including responsibilities, profit sharing, and compliance requirements.
find out more
Project Agreement Between Two Companies
An Indian law-governed agreement between two companies defining terms, conditions, and responsibilities for a specific project collaboration.
find out more
Construction Disbursement Agreement
An Indian law-governed agreement that regulates the disbursement of construction finance based on project milestones and compliance requirements.
find out more
Real Estate Development Term Sheet
An Indian law-governed preliminary agreement outlining key terms and conditions for real estate development projects.
find out more
Program Management Agreement
An Indian law-governed agreement establishing terms for professional program management services, including scope, governance, and delivery responsibilities.
find out more
Real Estate Development Partnership Agreement
An Indian law-governed agreement establishing partnership terms for real estate development projects, including capital contributions, profit sharing, and regulatory compliance.
find out more
Real Estate Development Joint Venture Term Sheet
An Indian law-governed preliminary agreement outlining key terms for a real estate development joint venture, serving as the basis for detailed transaction documents.
find out more
Business Consortium Agreement
An Indian law-governed agreement establishing terms and conditions for business consortium arrangements between multiple parties, including governance, resources, and profit-sharing structures.
find out more
Operation And Maintenance Agreement Solar Power Plant
Operation and Maintenance Agreement for Solar Power Plants under Indian jurisdiction, establishing framework for maintenance services and operational standards.
find out more
Project Employment Contract
An Indian law-governed employment agreement for project-based work that defines terms, conditions, and duration of temporary employment.
find out more
Project Joint Venture Agreement
An Indian law-governed agreement establishing a joint venture between parties for executing a specific project, detailing contributions, responsibilities, and project execution terms.
find out more
Construction Subcontracts
An Indian law-governed agreement between main contractor and subcontractor defining construction work scope, terms, and compliance requirements.
find out more
Building Construction Agreement
An Indian law-governed agreement between property owner/developer and contractor establishing terms for building construction works.
find out more
Project Alliance Agreement
An Indian law-governed collaborative agreement for project delivery through risk and reward sharing between multiple parties.
find out more
Consortium Agreement Construction Project
An Indian law-governed agreement establishing a consortium for construction project execution, defining member relationships, responsibilities, and operational framework.
find out more
Project Profit Sharing Agreement
An Indian law-governed agreement establishing profit sharing arrangements between parties involved in a specific project, including calculation methods and distribution mechanisms.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)