The Roofing Subcontractor Agreement is essential for construction projects in Malaysia where specialized roofing work is required. This document is typically used when a main contractor needs to engage a specialized roofing contractor for specific aspects of a construction project. The agreement ensures compliance with Malaysian construction laws, including CIDB regulations and local building codes, while clearly defining the scope of work, quality standards, safety requirements, and commercial terms. It provides necessary legal protection for both parties and establishes clear guidelines for project execution, payment terms, and dispute resolution procedures. The document is particularly important given the technical nature of roofing work and the specific safety considerations required under Malaysian law.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Genie AI's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identifies the main contractor and roofing subcontractor, including registration numbers and business addresses
2. Background: Context of the agreement, including details of the main project and principal contract
3. Definitions: Key terms used throughout the agreement
4. Scope of Work: Detailed description of roofing works to be performed, including type of roof, materials, and area coverage
5. Contract Sum and Payment Terms: Agreed price, payment schedule, and procedures for progress payments
6. Duration and Timeline: Project timeline, completion date, and any milestone dates
7. Materials and Workmanship: Quality standards, material specifications, and workmanship requirements
8. Safety Requirements: Safety protocols, PPE requirements, and compliance with OSHA regulations
9. Warranties and Defects: Warranty period, defects liability, and rectification procedures
10. Insurance and Indemnity: Required insurance coverage and indemnification obligations
11. Termination: Grounds and procedures for contract termination
12. Dispute Resolution: Process for handling disputes, including mediation and arbitration procedures
13. General Provisions: Standard contractual provisions including notices, governing law, and entire agreement
1. Performance Bond: Required for larger projects or when specified by the main contractor
2. Weather Conditions: Specific provisions for handling weather-related delays and impacts
3. Environmental Requirements: Include when project has specific green building or environmental certifications
4. Subcontracting: Include if the roofing subcontractor may need to further subcontract specialized aspects
5. Storage and Security: Required when on-site storage of materials is necessary
6. Variations: Detailed procedure for handling variations when complex changes are anticipated
7. Testing and Commissioning: Include for complex roofing systems requiring specific testing procedures
1. Schedule 1 - Scope of Works: Detailed specifications of roofing works, including drawings and technical requirements
2. Schedule 2 - Bill of Quantities: Itemized list of materials, quantities, and rates
3. Schedule 3 - Project Timeline: Detailed project schedule with milestones and completion dates
4. Schedule 4 - Payment Schedule: Breakdown of payment terms, including progress payment milestones
5. Schedule 5 - Safety Requirements: Detailed safety procedures and requirements specific to the roofing work
6. Schedule 6 - Material Specifications: Detailed specifications for all roofing materials to be used
7. Appendix A - Site Plans: Relevant architectural drawings and site plans
8. Appendix B - Insurance Requirements: Detailed insurance coverage requirements and certificates
9. Appendix C - Quality Assurance Procedures: Specific quality control and testing requirements
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate Development
Industrial Manufacturing
Commercial Property
Residential Development
Infrastructure
Retail
Hospitality
Education
Healthcare
Relevant Teams
Legal
Operations
Construction
Procurement
Risk & Compliance
Commercial
Health & Safety
Project Management
Technical
Quality Assurance
Relevant Roles
Project Manager
Construction Manager
Contracts Manager
Legal Counsel
Quantity Surveyor
Site Supervisor
Safety Officer
Procurement Manager
Technical Director
Operations Manager
Risk Manager
Commercial Manager
Project Engineer
Construction Director
Compliance Officer
Find the exact document you need
Home Builder Subcontractor Agreement
A Malaysian law-governed agreement between main contractor and subcontractor for residential construction works, complying with local construction and housing development regulations.
find out more
Contractor Service Contract
Malaysian law-governed agreement establishing terms between a company and independent contractor, defining service provisions and relationship parameters.
find out more
Independent Contractor Therapist Agreement
Malaysian-law governed agreement establishing an independent contractor relationship between a healthcare facility and a therapist.
find out more
Contractor Architect Agreement
A Malaysian law-governed agreement between a client and an architect contractor defining architectural services, obligations, and commercial terms.
find out more
Contract For Work For Hire
A Malaysian law-governed agreement establishing terms for commissioned work, including ownership transfer, payment, and delivery obligations.
find out more
Simple Building Contract
A Malaysian law-governed construction agreement for straightforward building projects, establishing key terms between employer and contractor.
find out more
Basic Independent Contractor Agreement
A Malaysian law-governed agreement establishing the terms and conditions between a business and an independent contractor, ensuring clear definition of services and compliance with local regulations.
find out more
Self Employed Service Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a service provider and client company, defining services, terms, and obligations.
find out more
Contractor Deposit Agreement
A Malaysian law-governed agreement establishing terms for contractor deposits in construction projects, including payment, holding, and release conditions.
find out more
Developer Contractor Agreement
Malaysian-law governed agreement for engaging software development contractors, defining service terms and protecting both parties' interests.
find out more
Home Contractor Contract
A Malaysian law-governed contract between homeowner and contractor for residential construction works, including terms, conditions, and regulatory compliance requirements.
find out more
Standard Independent Contractor Contract
A Malaysian law-governed agreement establishing terms and conditions between a company and an independent contractor for professional services.
find out more
Agreement Between Owner And Electrical Contractor
A Malaysian law-governed agreement between property owner and electrical contractor defining terms, scope, and compliance requirements for electrical installation works.
find out more
Service Of Work Contract
A Malaysian law-governed agreement establishing terms and conditions for service provision between a service provider and client.
find out more
Residential Building Contract Agreement
A Malaysian law-governed agreement between property owner and contractor for residential construction works, ensuring compliance with local construction regulations and standards.
find out more
Agreement Between Owner And Labour Contractor
A Malaysian law-governed agreement between project owners and labor contractors establishing terms for workforce services and regulatory compliance.
find out more
Massage Contractor Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a business and a massage therapist, defining service terms and operational requirements.
find out more
Short Form Contractor Agreement
A streamlined contractor agreement template for Malaysian jurisdiction, designed for engaging independent contractors or service providers.
find out more
Home Painting Contract
A Malaysian law-governed contract for residential painting services, establishing terms between contractors and property owners.
find out more
Home Improvement Agreement
A Malaysian law-governed agreement between homeowner and contractor for residential improvement works, detailing project scope, terms, and obligations.
find out more
Freelance Contractor Agreement
A Malaysian law-governed agreement establishing terms between a client and freelance contractor, defining services, payments, and obligations.
find out more
Subcontractor Employment Agreement
Malaysian-law governed agreement establishing subcontractor relationship and terms of service provision.
find out more
Simple Payment Agreement Contract
A Malaysian law-governed agreement establishing payment terms and obligations between parties.
find out more
Independent Contractor And Non Compete
Malaysian law-compliant agreement for engaging independent contractors with non-compete provisions to protect business interests.
find out more
Contractor Service Agreement
A Malaysian law-governed agreement establishing terms and conditions between a client company and an independent contractor for professional services.
find out more
Consulting Agreement Contract
A Malaysian law-governed agreement defining the terms and conditions between a consultant and client, including service scope, payments, and obligations.
find out more
Standard Form Of Contract For Maintenance And Renovation Works
A Malaysian standard form contract template for maintenance and renovation works, establishing terms and conditions between property owners and contractors.
find out more
Standard Builders Contract
A Malaysian law-governed construction contract defining the relationship between employer and contractor for building projects, aligned with CIDB requirements.
find out more
Simple Contractor Contract
A Malaysian law-governed contractor agreement establishing independent service provider relationships while ensuring legal compliance and protecting both parties' interests.
find out more
Self Employed Cleaner Contract
Malaysian-compliant contract template for engaging self-employed cleaning contractors, establishing service terms and independent contractor status.
find out more
Sales Subcontractor Agreement
Malaysian-law governed agreement establishing terms for sales subcontractor relationships, including commission structures, territories, and performance requirements.
find out more
Percentage Agreement Contract
A Malaysian law-governed agreement establishing percentage-based commercial terms between parties, including calculation methods and payment structures.
find out more
Painting Subcontractor Contract
A Malaysian law-governed contract establishing terms and conditions for painting subcontractor works in construction projects.
find out more
Part Time Contractor Agreement
Malaysian-law governed agreement for engaging part-time independent contractors, defining service terms and maintaining contractor independence.
find out more
General Contract For Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for service provision between a provider and client.
find out more
General Contract Agreement Between Two Parties
A versatile contract template under Malaysian law establishing legal terms and conditions between two contracting parties.
find out more
Contract For Cleaning Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for professional cleaning services between service providers and clients.
find out more
Construction Service Contract
A Malaysian law-governed agreement establishing terms and conditions for construction services between an employer and contractor.
find out more
Contract Agreement For Interior Works
A Malaysian law-governed agreement establishing terms and conditions for interior works projects, including scope, payments, and obligations of all parties.
find out more
Contractor Non Solicitation Agreement
A Malaysian law-governed agreement preventing contractors from soliciting company employees, clients, or customers during and after their engagement.
find out more
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)