The General Contractor Contract With Owner is a fundamental legal document used in Pakistan's construction industry to establish and regulate the relationship between property owners and construction contractors. This contract type is essential when an owner requires comprehensive construction services and wants to delegate the responsibility for project execution to a single contractor. It is designed to comply with Pakistani legal requirements, including the Contract Act 1872, Pakistan Engineering Council regulations, and national building codes. The document typically includes detailed provisions for scope of work, payment terms, project timeline, quality standards, safety requirements, and dispute resolution mechanisms. It's particularly important for projects where the owner wants to maintain overall control while transferring construction risk and responsibility to the contractor. The contract serves both small-scale residential projects and large commercial developments, adapting to various project sizes while maintaining the essential legal framework required under Pakistani law.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the Owner and the General Contractor, including their legal status and registered addresses
2. Background: Context of the agreement, including project overview and the basis for entering into the contract
3. Definitions: Detailed definitions of terms used throughout the contract to ensure clarity and prevent misinterpretation
4. Scope of Work: Detailed description of the construction work to be performed, including general obligations of the contractor
5. Contract Price and Payment Terms: Fixed price or cost structure, payment schedule, invoicing requirements, and payment conditions
6. Project Timeline: Commencement date, completion date, project phases, and milestones
7. Contractor's Obligations: Detailed responsibilities including quality standards, supervision, safety measures, and compliance requirements
8. Owner's Obligations: Owner's responsibilities including site access, permits, approvals, and owner-supplied materials if any
9. Materials and Workmanship: Quality standards, inspection requirements, and approval processes for materials and work
10. Variations and Changes: Procedures for handling changes to scope, pricing, or timeline, including change order process
11. Health and Safety: Safety requirements, compliance with regulations, and responsibility for site safety
12. Insurance and Indemnities: Required insurance coverage and indemnification obligations of both parties
13. Warranties and Defects Liability: Warranty terms, defects liability period, and rectification obligations
14. Termination: Grounds for termination, termination procedures, and consequences
15. Force Majeure: Definition of force majeure events and their impact on contractual obligations
16. Dispute Resolution: Process for resolving disputes, including mediation, arbitration, and jurisdiction
17. Governing Law: Specification of Pakistani law as governing law and relevant jurisdictional details
18. Notices: Format and procedure for official communications between parties
19. General Provisions: Standard boilerplate clauses including assignment, waiver, and severability
1. Subcontracting: Include when subcontracting is permitted, specifying approval requirements and contractor's liability for subcontractors
2. Equipment and Temporary Works: Include when significant temporary works or specific equipment requirements need to be detailed
3. Environmental Compliance: Include for projects with significant environmental impact or specific environmental requirements
4. Security and Performance Bonds: Include when performance bonds or other security instruments are required
5. Intellectual Property Rights: Include when design elements or proprietary methods are involved
6. Site Conditions: Include when specific site conditions need special attention or risk allocation
7. Quality Assurance Program: Include for complex projects requiring specific quality management systems
8. Training and Technology Transfer: Include when owner's staff training or technology transfer is part of the scope
9. Local Content Requirements: Include when there are specific requirements for local material or labor usage
10. Advance Payment: Include when advance payments are part of the payment structure
1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings of the works to be performed
2. Schedule 2 - Bill of Quantities: Itemized list of quantities, unit rates, and prices for the works
3. Schedule 3 - Project Timeline: Detailed project schedule including milestones and critical path activities
4. Schedule 4 - Payment Schedule: Detailed breakdown of payment terms, milestones, and conditions
5. Schedule 5 - Key Personnel: List of key personnel from both parties with roles and responsibilities
6. Schedule 6 - Required Insurance: Detailed insurance requirements including types and coverage amounts
7. Schedule 7 - Forms and Procedures: Standard forms for variations, claims, completion certificates, etc.
8. Schedule 8 - Site Information: Site details, access points, restrictions, and existing conditions
9. Schedule 9 - Quality Control Requirements: Detailed quality control procedures and acceptance criteria
10. Appendix A - Required Permits and Approvals: List of required permits and party responsible for obtaining them
11. Appendix B - Health and Safety Requirements: Detailed safety procedures and requirements
12. Appendix C - Environmental Management Plan: Environmental protection requirements and procedures
Find the exact document you need
Agreement Between Builder And Labour Contractor
A Pakistani law-governed agreement between builders and labor contractors defining terms for construction workforce services, including responsibilities, payments, and compliance requirements.
Download
Basic General Contractor Agreement
A Pakistani law-governed agreement between property owners and general contractors defining terms and conditions for construction projects.
Download
Cleaning Subcontractor Contract
A Pakistani law-governed agreement between a main contractor and cleaning subcontractor defining terms for cleaning service provision and operational requirements.
Download
Contract Between Employer And Contractor
A Pakistani law-governed agreement establishing terms and conditions between an employer and contractor, defining work scope, payments, and mutual obligations.
Download
Electrical Contractor Agreement
A Pakistani law-governed agreement between client and electrical contractor for electrical services, incorporating local regulatory requirements and industry standards.
Download
Contractor Service Contract
A Pakistani law-governed agreement establishing terms and conditions between a client and an independent contractor for the provision of specific services.
Download
Labour Contract Form
A legally binding employment agreement compliant with Pakistani labor laws that establishes terms and conditions between employer and employee.
Download
Contractor Agreement For House (Construction)
A Pakistani law-governed agreement between property owner and contractor for residential construction, detailing project scope, terms, and mutual obligations.
Download
Contractor Deposit Agreement
A Pakistan-compliant agreement governing contractor security deposits, their maintenance, and return conditions.
Download
Building Construction Labour Contract Agreement
A standardized labor contract agreement for construction workers in Pakistan, ensuring compliance with local labor laws and construction regulations.
Download
Home Contractor Contract
A Pakistani law-governed contract between homeowner and contractor for residential construction/renovation work, outlining project terms, obligations, and deliverables.
Download
Standard Independent Contractor Contract
A Pakistani law-governed agreement establishing an independent contractor relationship, defining services, payments, and obligations while ensuring legal compliance.
Download
Real Estate Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for construction works, detailing project terms, conditions, and regulatory compliance requirements.
Download
Agreement Between Owner And Electrical Contractor
A comprehensive contract governing electrical works between property owners and contractors in Pakistan, ensuring compliance with local regulations and safety standards.
Download
Standard Contractor Contract
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring legal compliance while defining service scope and relationship parameters.
Download
Generic Contractor Agreement
A Pakistan-law compliant agreement establishing terms and conditions between a hiring entity and an independent contractor, covering work scope, payments, and legal obligations.
Download
Independent Service Contract
A Pakistani law-governed agreement establishing terms and conditions between an independent service provider and client, defining service scope, payments, and contractual obligations.
Download
Agreement Between Company And Labour Contractor
A legal agreement under Pakistani law governing the relationship between a company and labor contractor for workforce provision and management.
Download
Construction Agreement Form
A comprehensive construction agreement template compliant with Pakistani law, establishing terms and conditions between contractors and clients for construction projects.
Download
Freelance Contractor Agreement
A Pakistani law-compliant agreement establishing terms and conditions between a business and an independent contractor.
Download
Simple Subcontractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a main contractor and subcontractor for delegated work or services.
Download
Residential Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for residential construction works, detailing project scope, terms, and obligations.
Download
Labour Hire Contract
A Pakistani law-compliant agreement establishing terms for labor hire arrangements between a labor hire company, worker, and client company.
Download
Consulting Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions between a consultant and client for professional consulting services.
Download
Construction Contractor Contract
A Pakistani law-governed agreement between a construction contractor and project owner, defining construction project terms, obligations, and execution requirements.
Download
Startup Contractor Agreement
A Pakistan-law governed contractor agreement for startups engaging independent professionals, ensuring legal compliance while maintaining startup-appropriate flexibility.
Download
Standard Builders Contract
A Pakistani law-governed construction agreement establishing rights and obligations between employer and contractor for building projects, aligned with local regulations and industry standards.
Download
Percentage Agreement Contract
A Pakistani law-governed agreement establishing percentage-based commercial relationships, detailing calculation methods and payment terms for revenue or profit sharing arrangements.
Download
Part Time Contractor Agreement
Pakistani law-compliant agreement establishing terms and conditions for part-time contractor engagement, including scope, payment, and legal obligations.
Download
Independent Employment Agreement
A Pakistani law-governed agreement establishing an independent contractor relationship between a company and a service provider, defining services, compensation, and compliance requirements.
Download
Home Remodel Contract
A Pakistani law-governed contract for home renovation projects between homeowners and contractors, outlining construction terms and obligations.
Download
Housekeeping Services Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions for professional housekeeping services, including service scope, requirements, and compliance with local regulations.
Download
General Contract Agreement Between Two Parties
A standard bilateral contract agreement compliant with Pakistani law, establishing terms and conditions for business relationships between two parties.
Download
Construction Service Contract
A Pakistani law-governed agreement establishing terms and conditions for construction services between contractor and client, ensuring regulatory compliance and project delivery standards.
Download
Confidentiality Agreement For Contractors
A Pakistan-law governed agreement establishing confidentiality obligations between a company and its contractors, protecting sensitive business information and trade secrets.
Download
Agreement For Construction Of House
A Pakistani law-governed agreement establishing terms and conditions for residential house construction, including specifications, timelines, and payment terms.
Download
Agreement Between Contractor And Principal Employer
A Pakistan-law governed agreement establishing terms and conditions between a Principal Employer and Contractor for professional services.
Download
Truck Driver Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent truck driver contractor, covering operational, safety, and compliance requirements.
Download
Contract Agreement Between Contractor And Client
A Pakistani law-governed agreement establishing terms and conditions between a client and contractor for professional services or project delivery.
Download
Hourly Independent Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions for hourly-based independent contractor services.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)