The Simple Construction Contract is designed for use in Pakistan's construction industry where a straightforward yet comprehensive agreement is needed for construction projects of moderate scope and complexity. This document type is particularly suitable when there is a clear understanding of the project requirements and when the construction work can be well-defined from the outset. The contract incorporates essential elements required under Pakistani law, including the Contract Act 1872 and relevant building regulations, while maintaining simplicity in its structure and terms. It is commonly used for residential and small commercial construction projects, renovations, and similar works where the sophisticated mechanisms of more complex construction contracts would be unnecessary. The document provides adequate protection for both parties while avoiding the complexity of larger-scale construction contracts, making it ideal for projects where the employer and contractor seek a balanced and straightforward legal framework.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the contracting parties (employer and contractor)
2. Background: Context of the agreement and brief description of the construction project
3. Definitions: Definitions of key terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed
5. Contract Price and Payment Terms: Amount to be paid and payment schedule, including any advance payments and retention amounts
6. Timeline and Completion: Project schedule, completion date, and provisions for extensions of time
7. Contractor's Obligations: Key responsibilities of the contractor including quality standards, safety measures, and compliance requirements
8. Employer's Obligations: Key responsibilities of the employer including site access, permits, and approvals
9. Materials and Workmanship: Standards for materials and quality of work required
10. Variations: Process for handling changes to the scope of work
11. Defects Liability: Contractor's responsibility for rectifying defects during the defects liability period
12. Insurance and Indemnity: Required insurance coverage and indemnification obligations
13. Termination: Grounds and procedures for contract termination
14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
15. Governing Law: Specification of Pakistani law as the governing law
16. Notices: Process and addresses for serving notices under the contract
1. Performance Security: Requirements for performance bonds or guarantees - used for larger projects or where required by the employer
2. Advance Payment Guarantee: Terms for advance payment security - included when advance payments are part of the payment structure
3. Liquidated Damages: Pre-agreed damages for delay or specific breaches - used when quantifiable losses can be predicted
4. Force Majeure: Provisions for unforeseen circumstances - particularly important in longer-term projects
5. Site Conditions: Provisions dealing with ground conditions and site investigations - used when there are significant ground works
6. Subcontracting: Rules and limitations on subcontracting - included when subcontracting is likely
7. Environmental Compliance: Specific environmental obligations - included when project has significant environmental impact
8. Health and Safety: Detailed safety requirements - expanded section for high-risk construction works
9. Quality Assurance: Detailed quality control procedures - used for complex projects requiring specific quality standards
1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings of the works to be performed
2. Schedule 2 - Project Timeline: Detailed project schedule including milestones and completion dates
3. Schedule 3 - Payment Schedule: Breakdown of payment installments and payment milestones
4. Schedule 4 - Site Details: Site plan, access points, and any relevant site conditions
5. Schedule 5 - Material Specifications: Detailed specifications for materials to be used in the construction
6. Schedule 6 - Key Personnel: List of key personnel from both parties involved in the project
7. Schedule 7 - Forms of Certificates: Template certificates for completion, payment, and acceptance
8. Schedule 8 - Insurance Requirements: Detailed insurance requirements and minimum coverage amounts
9. Appendix A - Required Permits: List of required permits and responsibilities for obtaining them
10. Appendix B - Safety Standards: Specific safety standards and procedures to be followed
Find the exact document you need
Agreement Between Builder And Labour Contractor
A Pakistani law-governed agreement between builders and labor contractors defining terms for construction workforce services, including responsibilities, payments, and compliance requirements.
Download
Basic General Contractor Agreement
A Pakistani law-governed agreement between property owners and general contractors defining terms and conditions for construction projects.
Download
Cleaning Subcontractor Contract
A Pakistani law-governed agreement between a main contractor and cleaning subcontractor defining terms for cleaning service provision and operational requirements.
Download
Contract Between Employer And Contractor
A Pakistani law-governed agreement establishing terms and conditions between an employer and contractor, defining work scope, payments, and mutual obligations.
Download
Electrical Contractor Agreement
A Pakistani law-governed agreement between client and electrical contractor for electrical services, incorporating local regulatory requirements and industry standards.
Download
Contractor Service Contract
A Pakistani law-governed agreement establishing terms and conditions between a client and an independent contractor for the provision of specific services.
Download
Labour Contract Form
A legally binding employment agreement compliant with Pakistani labor laws that establishes terms and conditions between employer and employee.
Download
Contractor Agreement For House (Construction)
A Pakistani law-governed agreement between property owner and contractor for residential construction, detailing project scope, terms, and mutual obligations.
Download
Contractor Deposit Agreement
A Pakistan-compliant agreement governing contractor security deposits, their maintenance, and return conditions.
Download
Building Construction Labour Contract Agreement
A standardized labor contract agreement for construction workers in Pakistan, ensuring compliance with local labor laws and construction regulations.
Download
Home Contractor Contract
A Pakistani law-governed contract between homeowner and contractor for residential construction/renovation work, outlining project terms, obligations, and deliverables.
Download
Standard Independent Contractor Contract
A Pakistani law-governed agreement establishing an independent contractor relationship, defining services, payments, and obligations while ensuring legal compliance.
Download
Real Estate Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for construction works, detailing project terms, conditions, and regulatory compliance requirements.
Download
Agreement Between Owner And Electrical Contractor
A comprehensive contract governing electrical works between property owners and contractors in Pakistan, ensuring compliance with local regulations and safety standards.
Download
Standard Contractor Contract
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent contractor, ensuring legal compliance while defining service scope and relationship parameters.
Download
Generic Contractor Agreement
A Pakistan-law compliant agreement establishing terms and conditions between a hiring entity and an independent contractor, covering work scope, payments, and legal obligations.
Download
Independent Service Contract
A Pakistani law-governed agreement establishing terms and conditions between an independent service provider and client, defining service scope, payments, and contractual obligations.
Download
Agreement Between Company And Labour Contractor
A legal agreement under Pakistani law governing the relationship between a company and labor contractor for workforce provision and management.
Download
Construction Agreement Form
A comprehensive construction agreement template compliant with Pakistani law, establishing terms and conditions between contractors and clients for construction projects.
Download
Freelance Contractor Agreement
A Pakistani law-compliant agreement establishing terms and conditions between a business and an independent contractor.
Download
Simple Subcontractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a main contractor and subcontractor for delegated work or services.
Download
Residential Contractor Agreement
A Pakistani law-governed agreement between property owner and contractor for residential construction works, detailing project scope, terms, and obligations.
Download
Labour Hire Contract
A Pakistani law-compliant agreement establishing terms for labor hire arrangements between a labor hire company, worker, and client company.
Download
Consulting Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions between a consultant and client for professional consulting services.
Download
Construction Contractor Contract
A Pakistani law-governed agreement between a construction contractor and project owner, defining construction project terms, obligations, and execution requirements.
Download
Startup Contractor Agreement
A Pakistan-law governed contractor agreement for startups engaging independent professionals, ensuring legal compliance while maintaining startup-appropriate flexibility.
Download
Standard Builders Contract
A Pakistani law-governed construction agreement establishing rights and obligations between employer and contractor for building projects, aligned with local regulations and industry standards.
Download
Percentage Agreement Contract
A Pakistani law-governed agreement establishing percentage-based commercial relationships, detailing calculation methods and payment terms for revenue or profit sharing arrangements.
Download
Part Time Contractor Agreement
Pakistani law-compliant agreement establishing terms and conditions for part-time contractor engagement, including scope, payment, and legal obligations.
Download
Independent Employment Agreement
A Pakistani law-governed agreement establishing an independent contractor relationship between a company and a service provider, defining services, compensation, and compliance requirements.
Download
Home Remodel Contract
A Pakistani law-governed contract for home renovation projects between homeowners and contractors, outlining construction terms and obligations.
Download
Housekeeping Services Agreement Contract
A Pakistani law-governed agreement establishing terms and conditions for professional housekeeping services, including service scope, requirements, and compliance with local regulations.
Download
General Contract Agreement Between Two Parties
A standard bilateral contract agreement compliant with Pakistani law, establishing terms and conditions for business relationships between two parties.
Download
Construction Service Contract
A Pakistani law-governed agreement establishing terms and conditions for construction services between contractor and client, ensuring regulatory compliance and project delivery standards.
Download
Confidentiality Agreement For Contractors
A Pakistan-law governed agreement establishing confidentiality obligations between a company and its contractors, protecting sensitive business information and trade secrets.
Download
Agreement For Construction Of House
A Pakistani law-governed agreement establishing terms and conditions for residential house construction, including specifications, timelines, and payment terms.
Download
Agreement Between Contractor And Principal Employer
A Pakistan-law governed agreement establishing terms and conditions between a Principal Employer and Contractor for professional services.
Download
Truck Driver Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions between a company and an independent truck driver contractor, covering operational, safety, and compliance requirements.
Download
Contract Agreement Between Contractor And Client
A Pakistani law-governed agreement establishing terms and conditions between a client and contractor for professional services or project delivery.
Download
Hourly Independent Contractor Agreement
A Pakistani law-governed agreement establishing terms and conditions for hourly-based independent contractor services.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it