The Civil Construction Contract Agreement is a fundamental legal document used in Qatar's construction industry to formalize the relationship between project owners and contractors. This agreement is essential for any significant construction project in Qatar, whether commercial, residential, or infrastructure development. It must comply with Qatar's Civil Code, Labor Law, and various construction-related regulations. The document typically includes detailed provisions for project execution, payment mechanisms, quality standards, safety requirements, and dispute resolution procedures. It's particularly important in Qatar's rapidly developing construction sector, where large-scale projects require robust legal frameworks to ensure successful project delivery and protect all parties' interests. The agreement incorporates local business practices and regulatory requirements while addressing specific challenges of construction projects in Qatar's unique environmental and regulatory context.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the contracting parties (Employer and Contractor)
2. Background: Context of the agreement and brief project overview
3. Definitions and Interpretation: Detailed definitions of terms used throughout the contract and rules of interpretation
4. Scope of Works: Detailed description of the construction works to be performed
5. Contract Price and Payment Terms: Payment amount, schedule, method, and conditions for payment
6. Project Timeline: Commencement date, completion date, and key milestones
7. Contractor's Obligations: General and specific obligations of the contractor, including quality standards and compliance requirements
8. Employer's Obligations: Responsibilities and obligations of the employer, including site access and permits
9. Materials and Workmanship: Standards for materials and workmanship, including testing and approval procedures
10. Variations: Procedures for handling changes to the scope of work
11. Health and Safety: Safety requirements and procedures in compliance with Qatar regulations
12. Insurance and Indemnities: Required insurance coverage and indemnification provisions
13. Warranties and Defects Liability: Warranty terms and defect rectification procedures
14. Suspension and Termination: Grounds and procedures for contract suspension and termination
15. Force Majeure: Definition and consequences of force majeure events
16. Dispute Resolution: Procedures for resolving disputes, including arbitration provisions
17. Governing Law: Confirmation of Qatar law as governing law and jurisdiction
18. General Provisions: Standard boilerplate clauses including notices, assignments, and amendments
1. Performance Security: Required when project value exceeds certain thresholds or when specified by employer
2. Advance Payment: Included when advance payments are part of the payment structure
3. Liquidated Damages: Specific provisions for compensation in case of delays or performance failures
4. Site Conditions: Detailed when special site conditions need specific attention or risk allocation
5. Environmental Requirements: Required for projects with significant environmental impact
6. Local Content Requirements: Included when project must meet specific Qatari local content requirements
7. Intellectual Property Rights: Required when design or innovative construction methods are involved
8. Confidentiality: Included for projects involving sensitive information or proprietary methods
1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings
2. Schedule 2 - Contract Price Breakdown: Detailed breakdown of contract price and bill of quantities
3. Schedule 3 - Project Timeline: Detailed project schedule with milestones and critical path
4. Schedule 4 - Key Personnel: List of key personnel from both parties with roles and responsibilities
5. Schedule 5 - Required Insurances: Detailed insurance requirements and coverage levels
6. Schedule 6 - Forms of Certificates: Templates for various certificates including completion certificates
7. Schedule 7 - Quality Assurance Requirements: Detailed quality control and assurance procedures
8. Schedule 8 - HSE Requirements: Detailed health, safety, and environmental requirements
9. Schedule 9 - Performance Security Forms: Templates for bank guarantees and performance bonds
10. Schedule 10 - Permits and Licenses: List of required permits and responsibilities for obtaining them
11. Appendix A - Site Plan and Drawings: Technical drawings and site layout plans
12. Appendix B - Material Specifications: Detailed specifications for construction materials
13. Appendix C - Testing and Commissioning Procedures: Procedures for testing and commissioning works
Find the exact document you need
Contractor Agreement For House (Construction)
Qatar-governed construction contract between property owner and contractor for residential house building, outlining project terms, specifications, and obligations.
Download
Project Labor Agreement
Qatar-governed labor agreement establishing terms and conditions for construction project workforce management and compliance with local labor laws.
Download
Joint Venture Agreement For (Construction)
A Qatar-law governed agreement establishing a joint venture between parties for construction projects, addressing operational, financial, and regulatory requirements under Qatar law.
Download
Contract For Project Management Services
Qatar-law governed agreement for professional project management services, defining scope, responsibilities, and delivery terms.
Download
Project Based Employment Agreement
Qatar law-governed employment agreement for project-based work, combining standard employment terms with project-specific provisions and deliverables.
Download
Civil Construction Contract Agreement
A Qatar law-governed agreement establishing terms and conditions for civil construction projects, outlining parties' rights, obligations, and project requirements.
Download
Project Partnering Agreement
A Qatar law-governed agreement establishing project partnership terms and collaborative framework between multiple parties for project execution.
Download
Simple Construction Agreement
Qatar law-governed construction agreement establishing core rights and obligations between employer and contractor for construction projects.
Download
Building Construction Agreement
Qatar-law governed agreement setting out terms and conditions between an employer and contractor for building construction works.
Download
Project Alliance Agreement
A collaborative agreement under Qatar law establishing a project alliance framework between multiple parties for complex project delivery, incorporating shared risks and rewards.
Download
Construction Agreement Between Owner And Contractor
A Qatar law-governed agreement between owner and contractor defining terms, conditions, and obligations for construction works execution.
Download
Building Work Agreement
A Qatar law-governed agreement establishing terms and conditions between an employer and contractor for construction works, incorporating local legal requirements and construction practices.
Download
New Home Construction Agreement
Qatar-governed agreement for new residential property construction, defining contractor and owner obligations, construction specifications, and compliance requirements.
Download
Construction Lease Agreement
A Qatar-law governed agreement combining construction and lease terms for property development and subsequent occupancy.
Download
Minor Works Agreement
Qatar-law compliant agreement template for small to medium-scale construction works, establishing key terms between employer and contractor.
Download
Project Service Agreement
A Qatar law-governed agreement defining terms and conditions for project service delivery, including scope, payments, and performance standards.
Download
Joint Venture Agreement For Land Development
Qatar-law governed agreement establishing a joint venture between parties for land development projects, incorporating local regulatory and Sharia law compliance.
Download
Electrical Subcontractor Agreement
Qatar-law governed agreement between main contractor and electrical subcontractor for electrical installation works, incorporating local regulatory requirements and standards.
Download
Construction Non Disclosure Agreement
Qatar-law governed confidentiality agreement for construction projects, protecting sensitive project information and technical documentation.
Download
Construction Project Agreement
Qatar-law governed agreement setting out terms and conditions for construction project execution, including scope, payments, timelines, and compliance with local regulations.
Download
Software Implementation Agreement
Qatar-law governed agreement for software implementation projects, defining implementation terms, obligations, and deliverables between provider and client.
Download
Project Finance Loan Agreement
A Qatar law-governed loan agreement setting out terms and conditions for project financing, incorporating local legal requirements, security arrangements, and regulatory compliance measures.
Download
Project Cooperation Agreement
A Qatari law-governed agreement establishing terms and framework for multi-party project collaboration, including responsibilities, governance, and risk allocation.
Download
Project Agreement Contract
A Qatar law-governed agreement establishing the framework for project execution, including scope, responsibilities, and commercial terms.
Download
New Construction Agreement
Qatar-law governed agreement establishing terms and conditions for new construction projects, defining rights and obligations between employer and contractor.
Download
Construction Settlement Agreement
A Qatar law-governed agreement that documents the settlement terms and conditions for resolving construction project disputes between contracting parties.
Download
Renovation Agreement
A Qatar law-governed agreement setting out terms and conditions for property renovation works, including scope, payment, and compliance with local construction regulations.
Download
Demolition Agreement
A Qatar-law governed agreement setting out terms and conditions for demolition works, including safety, environmental, and regulatory compliance requirements.
Download
Construction Partnership Agreement
Qatar-law governed agreement establishing a partnership structure for construction projects, detailing operational and financial arrangements between partners.
Download
Consortium Agreement Between Companies
A Qatar law-governed agreement establishing a consortium between multiple companies, defining their rights, obligations, and collaborative framework.
Download
Remodeling Contractor Agreement
Qatar-law governed agreement between property owner and contractor for remodeling works, including scope, terms, and local compliance requirements.
Download
General Construction Agreement
A Qatar law-governed agreement between an employer and contractor establishing terms and conditions for construction works, including scope, payment, and obligations.
Download
Proof Of Concept Agreement
A Qatar law-governed agreement for testing and validating specific concepts or technologies, outlining testing parameters and parties' obligations.
Download
Project Confidentiality Agreement
Qatar law-governed confidentiality agreement protecting sensitive project information between collaborating parties.
Download
Pre Construction Agreement
A Qatar-law governed agreement establishing the framework for pre-construction services, including design review, cost planning, and construction methodology development.
Download
Contract Agreement For Construction Work
A Qatar law-governed agreement establishing terms and conditions between employer and contractor for construction works, including scope, payment, timeline, and compliance requirements.
Download
Construction Letter Of Intent
A preliminary contractual document under Qatar law establishing intent to enter into a formal construction contract and potentially authorizing initial works.
Download
Construction Management Contract
Qatar law-governed agreement appointing a construction manager to oversee and manage construction projects, detailing services, responsibilities, and compliance requirements.
Download
Cost Plus Construction Agreement
Qatar law-governed agreement for construction projects structured on a cost-plus basis, detailing cost reimbursement and contractor's fee arrangements.
Download
Website Development Agreement
A Qatar-law governed agreement establishing terms and conditions for website development services, including scope, deliverables, and compliance requirements.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)