The Standard Renovation Contract is designed for use in New Zealand construction projects involving building renovations, alterations, or improvements to existing structures. This document is particularly valuable when engaging contractors for residential or commercial renovation works valued above NZD $30,000, or for any project requiring building consent. The Standard Renovation Contract incorporates all necessary provisions required by New Zealand law, including compliance with the Building Act 2004, Construction Contracts Act 2002, and relevant consumer protection legislation. It provides comprehensive coverage of project specifications, payment terms, warranties, and dispute resolution procedures, while allowing flexibility for project-specific modifications. This contract type is essential for protecting both the property owner's and contractor's interests, ensuring clear communication of expectations, and establishing a legally sound framework for the renovation project.
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
Your data doesn't train Genie's AI
You keep IP ownership of your docs
1. Parties: Identification and details of the homeowner/client and the contractor, including legal names, addresses, and contact information
2. Background: Brief context of the renovation project and the agreement's purpose
3. Definitions: Key terms used throughout the contract defined for clarity and legal certainty
4. Scope of Works: Detailed description of the renovation work to be performed, including specific inclusions and exclusions
5. Contract Price: Total cost of the works, including payment schedule, deposit requirements, and progress payment terms
6. Timeframes: Project start date, completion date, and any milestone dates, including provisions for extensions of time
7. Contractor Obligations: Responsibilities of the contractor including workmanship, materials, compliance with building codes, and obtaining necessary permits
8. Client Obligations: Responsibilities of the client including site access, decisions, approvals, and existing condition declarations
9. Variations: Process for requesting, approving, and charging for changes to the original scope of works
10. Insurance and Risk: Required insurance coverage, liability provisions, and risk allocation between parties
11. Warranties: Workmanship guarantees, manufacturer warranties, and statutory warranties under NZ law
12. Dispute Resolution: Process for handling disputes, including mediation and arbitration procedures
13. Termination: Circumstances and process for contract termination by either party
14. General Provisions: Standard legal clauses including notices, governing law, and entire agreement provisions
1. Project Management: Details of project management structure and reporting requirements - used for larger renovation projects
2. Subcontractors: Terms regarding engagement and management of subcontractors - included when subcontractors will be used
3. Health and Safety: Specific health and safety requirements beyond standard obligations - used for complex or hazardous works
4. Consent Requirements: Detailed provisions about building consent processes - included when council permits are required
5. Provisional Sums: Estimates for uncertain aspects of the work - used when exact costs cannot be determined upfront
6. Materials Supply: Specific provisions about client-supplied materials - included when client is providing materials
7. Temporary Works: Provisions for temporary facilities or structures - used when significant temporary works are required
8. Defects Liability Period: Extended defects period beyond standard warranty - used for larger or complex renovations
1. Schedule 1: Scope of Works: Detailed specifications, plans, and drawings of the renovation work
2. Schedule 2: Price Breakdown: Itemized costs, including labor, materials, and any provisional sums
3. Schedule 3: Programme of Works: Detailed timeline showing sequence of works and major milestones
4. Schedule 4: Approved Plans: Architectural plans, engineering drawings, and council-approved documents
5. Schedule 5: Special Conditions: Any project-specific conditions or requirements
6. Appendix A: Site Safety Plan: Health and safety procedures specific to the site
7. Appendix B: Insurance Certificates: Copies of required insurance policies
8. Appendix C: Building Consents: Copies of building consents and related documentation
Find the exact document you need
Turnkey Contract
A New Zealand-governed contract for complete project delivery, where the contractor takes full responsibility from design through to commissioning.
Download
Time And Materials Contract
New Zealand-governed agreement for services provided on a time and materials basis, including labor rates, materials pricing, and performance requirements.
Download
Standard Renovation Contract
A New Zealand-compliant renovation contract template for structuring renovation projects, ensuring legal compliance with NZ construction and building laws.
Download
Swimming Pool Contract
A New Zealand-compliant swimming pool construction contract covering construction terms, safety requirements, and regulatory compliance under NZ law.
Download
Suppliers Contract Agreement
A New Zealand law-governed agreement establishing terms and conditions for the supply of goods/services between a supplier and purchaser.
Download
Sub Contractor Agreement
A New Zealand-compliant agreement establishing terms and conditions between a principal contractor and subcontractor, outlining services, payments, and obligations.
Download
Service Contract Proposal
A New Zealand-compliant service contract proposal outlining proposed service arrangements, terms, and conditions between service provider and client.
Download
Residential Solar Installation Contract
New Zealand-governed contract for residential solar system installation, covering installation terms, warranties, and regulatory compliance.
Download
Restoration Contract
A New Zealand-governed agreement setting out terms and conditions for property restoration works, including scope, payments, and compliance requirements.
Download
Receipt Contract
A New Zealand-compliant document evidencing a transaction between seller and buyer, including essential details required by local tax and commercial laws.
Download
Real Estate Contractor Agreement
A New Zealand-compliant agreement establishing the terms and conditions between a real estate agency and an independent contractor real estate agent.
Download
Proposal And Contract
A New Zealand law-governed document that combines a business proposal with contractual terms, creating a legally binding agreement upon acceptance.
Download
Private Contractor Agreement
A New Zealand-compliant agreement establishing the terms and conditions for engaging independent contractors, defining service scope, payment terms, and relationship parameters.
Download
Owner's Representative Contract
A New Zealand-compliant contract establishing the appointment and authority of an Owner's Representative for project oversight and management.
Download
New Home Construction Contract
A New Zealand-compliant contract for new residential property construction, establishing terms between builder and property owner.
Download
Masonry Contract
New Zealand-governed contract for masonry construction works, defining terms, specifications, and obligations between contractor and client.
Download
Marketing Agreement Contract
A New Zealand-governed agreement establishing terms between a marketing service provider and client for marketing services delivery and management.
Download
Lump Sum Contract
A New Zealand-governed fixed-price construction contract establishing terms for project delivery, payments, and risk allocation.
Download
Insurance Agency Agreement
A New Zealand-governed agreement establishing the legal relationship between an insurer and insurance agent/broker, outlining authorization terms and regulatory compliance requirements.
Download
Labour Only Subcontractor Agreement
A New Zealand-compliant agreement establishing terms and conditions between a principal contractor and labour-only subcontractor, ensuring legal and regulatory compliance.
Download
Labour Only Contract
A New Zealand-compliant employment agreement for labour-only services that establishes terms and conditions between an employer and employee.
Download
Kitchen Renovation Contract
A New Zealand-compliant contract governing the terms and conditions for kitchen renovation works between a contractor and property owner.
Download
Kitchen Contract
New Zealand-compliant contract template for kitchen installation and renovation projects, covering scope, costs, and responsibilities.
Download
Labour Supply Contract
New Zealand-governed agreement for the provision of temporary workers through a labor hire company to client organizations.
Download
Joint Contract
A New Zealand law-governed agreement establishing terms and conditions for joint arrangements between multiple parties, including shared responsibilities and obligations.
Download
Independent Contractor
New Zealand-compliant Independent Contractor Agreement defining service terms and maintaining contractor independence while ensuring legal compliance.
Download
Flooring Contract
New Zealand-compliant contract template for flooring installation and maintenance works, suitable for both residential and commercial projects.
Download
Fixed Price Building Contract
A New Zealand-compliant Fixed Price Building Contract establishing terms for construction works at an agreed fixed sum.
Download
Fence Contract
A New Zealand-compliant contract for fence construction and installation, outlining terms, specifications, and obligations between contractor and property owner.
Download
Employment Contract For Security Guard
New Zealand-compliant employment contract for security guard positions, incorporating industry-specific requirements and general employment terms.
Download
Excavation Contract
New Zealand-compliant contract template for excavation works, covering scope, safety, payments, and regulatory requirements.
Download
Cost Plus Fixed Fee Contract
New Zealand-compliant Cost Plus Fixed Fee Contract template establishing terms for cost reimbursement plus fixed fee compensation.
Download
Cost Plus Contract
A New Zealand law-governed agreement where the client pays the contractor's actual costs plus an agreed fee or percentage markup, suitable for projects with uncertain final costs.
Download
Contractor Payment Agreement
A New Zealand-compliant agreement establishing payment terms and conditions between a business and an independent contractor.
Download
Construction Contract
New Zealand construction contract template compliant with local legislation, governing construction project agreements between principals and contractors.
Download
Construction Bid Form
A standardized form used in New Zealand for submitting competitive construction project bids, ensuring compliance with local construction laws and procurement requirements.
Download
Contractor And Homeowner Agreement
A New Zealand-compliant legal agreement between a contractor and homeowner for residential construction or renovation work.
Download
Carpentry Contract
A New Zealand-compliant legal agreement for carpentry services, outlining work scope, terms, and obligations between carpenter and client.
Download
Bid Contract
A New Zealand law-governed contract that establishes terms and conditions for a competitive bidding process, including submission requirements and evaluation criteria.
Download
Bathroom Renovation Contract
A New Zealand-compliant contract governing the terms and conditions for bathroom renovation works between a contractor and property owner.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)